1. The contractor is granted access to the building and property with trucks and equipment for lifting and lowering material. The owner grants permission and is responsible for damage caused to the driveway, sidewalk, and landscaping by access to the building, property, and roof for these activities.
2. Spartan Exteriors LLC imposes a processing fee of 3% on the transaction amount of any credit card payments made to Spartan Exteriors LLC. The customer specifically authorizes Spartan Exteriors LLC to charge their credit card 3% of the transaction amount for the payments made by credit card.
3. All Proposals are subject to management approval.
4. All payments are to be made to Spartan Exteriors LLC.
5. Replacement of deteriorated decking, fascia, soffit, and all structural defects NOT included unless otherwise specified.
6. Spartan Exteriors LLC is not responsible for repositioning satellite(s) or damaging driveways.
7. For payments not received within 30 days, Spartan Exteriors LLC will charge the maximum interest allowed by law.
8. All warranties are null and void if full payment is not made after 60 days.
9. Replacement of deteriorated decking, fascia boards, roof jacks, ventilators, flashing, and other materials, unless otherwise specified in this contract are not included and any additional work will be agreed upon in advance with a change order and will be signed by both parties before work is started.
10. All leftover material is the property of Spartan Exteriors LLC.
11. Any representations or other communications not written in this contract are agreed to be immaterial and not relied on by either party and do not survive the execution of this contract.
12. Spartan Exteriors LLC is not responsible for fixing any damage caused by mold.
13. Spartan Exteriors LLC is not responsible for fixing any damage to A/C Lines or gas lines more than 4″ from the roof deck.
14. The customer may cancel this contract within 3 days from the date of signature. Written cancellation must be received by Spartan Exteriors LLC at the address above by the end of the third day or by verbal or written verification with your Spartan Exteriors LLC representative.

WARRANTY RIGHTS NOTIFICATION

1. Labor warranty does not cover anything that would be considered an insurance claim.
2. Spartan Exteriors LLC shall present manufacturer warranties for specific materials when specified in the contract. Spartan Exteriors LLC is responsible for the registration and execution of each.
3. Overdue balances shall suspend warranty rights until paid. Lapsed time shall not increase the length of any warranty or service agreement.
4. Spartan Exteriors LLC shall provide a written limited workmanship warranty when specified in the contract.
5. No other warranties are expressed or implied.

PRICE INCREASE LANGUAGE

Should it become necessary or proper for Spartan Exteriors LLC, during the term of this Agreement, to make any change in design, materials, price, or any alterations that will increase price, Spartan Exteriors LLC will notify Customer immediately. Price increases must be approved by Customer; however, if Customer does not approve any price increases within five(5) business days, Spartan Exteriors LLC shall have the right in its sole judgment to cancel the contract without penalty.

LIEN RIGHTS NOTIFICATION

AS REQUIRED BY THE TEXAS CONSTRUCTION LIEN LAW, SPARTAN EXTERIORS LLC. HEREBY NOTIFIES THE OWNER THAT PERSONS OR COMPANIES FURNISHING LABOR OR MATERIALS FOR THE CONSTRUCTION ON THE OWNER’S LAND MAY HAVE LIEN RIGHTS ON THE OWNER’S LAND AND BUILDINGS IF NOT PAID. THOSE ENTITLED TO LIEN RIGHTS, IN ADDITION TO THE UNDERSIGNED BUILDER, ARE THOSE WHO CONTRACT DIRECTLY WITH THE OWNER OR THOSE WHO GIVE THE OWNER NOTICE WITHIN 60 DAYS AFTER THEY FIRST FURNISH LABOR OR MATERIALS FOR THE CONSTRUCTION. ACCORDINGLY, OWNER PROBABLY WILL RECEIVE NOTICES FROM THOSE WHO FURNISH LABOR OR MATERIALS FOR THE CONSTRUCTION AND SHOULD GIVE A COPY OF EACH NOTICE RECEIVED TO HIS MORTGAGE LENDER, IF ANY. BUILDER AGREES TO COOPERATE WITH THE OWNER AND HIS LENDER, IF ANY, TO SEE THAT ALL POTENTIAL LIEN CLAIMANTS ARE DULY PAID.

If this Notice is attached to a written contract between the parties as owner and prime contractor, it becomes a part of the contract.

FORCE MAJEURE

Any delay or failure in the performance by Spartan Exteriors LLC hereunder shall be excused if and to the extent caused by the occurrence of a force majeure. For purposes of this Agreement, force majeure shall mean a cause or event that is not reasonably foreseeable or otherwise caused by or under the control of the party claiming force majeure, including acts of God, fires, floods, explosions, riots, wars, hurricanes, sabotage, terrorism, vandalism, accident, restraint of government, governmental acts, injunctions, labor strikes, and other like events that are beyond the reasonable anticipation and control of Spartan Exteriors LLC thereby, despite such Spartan Exteriors LLC reasonable efforts to prevent, avoid, delay, or mitigate the effect of such acts, events, or occurrences, and which events or the effects thereof are not attributable to a Spartan Exteriors LLC failure to perform its obligations under this Agreement.

ARBITRATION

15.8 Venue and Applicable Law. Client acknowledges that Spartan Exteriors LLC has appointed and intends to appoint many PPFs on terms and conditions similar to those set forth in this Agreement. It mutually benefits these PPF, and Client for Spartan Exteriors LLC terms and conditions of these license agreements are uniformly interpreted. This Agreement is accepted by Spartan Exteriors LLC in the Country of The United States of America and will be governed by the substantive laws of The State of Texas, without regard to the Client’s regional choice of law provisions. All issues or disagreements relating to this Agreement shall be mediated, arbitrated, tried, heard, and decided in the State of Texas, of The United States of America which the parties agree is the most convenient venue for these purposes. The client acknowledges and agrees that this location for a venue is reasonable and the most beneficial to the needs of and best meets the interests of the parties.